Loading...
Serving La Habra, CA and surrounding areas. (562) 245-5931
Effective date: January 1, 2026
By accessing or using the website at lahabrasunrooms.com, requesting a quote, or engaging La Habra Sunrooms and Patios ("Company," "we," "us," or "our") to perform any work, you ("Client") agree to be bound by these Terms and Conditions. If you do not agree to these terms, do not use our website or services.
These terms apply to all visitors to our website and to all clients who engage us for services. For contracted projects, the written project agreement signed by both parties governs the specific scope, pricing, and timeline of that project. In the event of a conflict between these general Terms and a signed project agreement, the signed agreement controls.
La Habra Sunrooms and Patios provides sunroom construction, patio enclosures, screen room installation, and related outdoor living improvement services for residential properties in the La Habra, California area and surrounding communities. Services are described in individual project proposals and contracts. We reserve the right to decline any project at our discretion.
We do not provide architectural or engineering services. Where engineering plans or calculations are required by the applicable building authority, we will identify this as part of the project scope and facilitate obtaining the required documentation from licensed professionals, the cost of which will be included in the project quote or stated separately.
Written estimates provided by La Habra Sunrooms and Patios are valid for 30 days from the date of issue unless otherwise stated in writing. Estimates are based on information available at the time of the site visit and written proposal. They are not final contracts and may be subject to adjustment if conditions discovered during construction differ materially from what was observable during the initial assessment.
We will notify you in writing before proceeding with any work that would increase the total project cost beyond what was quoted. Verbal price agreements are not binding. All price changes require a written change order signed by both parties before the additional work begins.
Permit fees, engineering fees, HOA submission fees, and inspection fees are either included in the quoted price or itemized separately. Please review your written proposal carefully to understand what is and is not included.
Project start dates are estimates and depend on permit approval, material availability, weather conditions, and the completion of prior projects. We will communicate scheduling updates to you as they arise.
If you need to reschedule a consultation or a project start, please provide at least 48 hours notice by phone or email. Cancellation of a signed project contract may result in cancellation fees as specified in the signed agreement, particularly if materials have been ordered or permit fees have been paid on your behalf.
We reserve the right to reschedule work due to weather conditions, crew availability, permit delays, or other circumstances outside our control. We will not be liable for delays caused by circumstances beyond our reasonable control.
Payment schedules are set forth in the signed project agreement. Typical projects require a deposit to begin, a progress payment at a defined milestone, and a final payment upon project completion. Specific amounts and timing are stated in your project contract.
Final payment is due upon project completion and before the delivery of any warranty documentation or final permit close-out documents. Overdue balances may be subject to interest at the maximum rate permitted by California law and may result in work stoppage until the balance is resolved.
We accept payment by check, bank transfer, and other methods specified in the project agreement. We do not accept cash-only arrangements for contracted projects.
For all permanent construction projects, we obtain the required building permits from the applicable city or county building authority. We do not perform permitted work without the proper permit in place. The client is responsible for any HOA approvals that may be required before permit submission, and we will advise you if this step is necessary for your project.
If a client requests that work be performed without permits where permits are legally required, we will decline that request. Performing unpermitted work where permits are required is a violation of California law and can create liability for both parties.
We warrant our workmanship for a period specified in your project agreement, typically one year from the date of project completion unless otherwise stated in writing. This warranty covers defects in installation and workmanship but does not cover damage caused by misuse, accidents, acts of nature (including earthquakes, flooding, or fire), failure to perform recommended maintenance, or modifications made by parties other than us.
Manufacturer warranties on materials and products are separate from our workmanship warranty and are governed by the terms of each manufacturer. We will provide you with applicable manufacturer warranty documentation upon project completion.
THE WEBSITE AND ITS CONTENT ARE PROVIDED "AS IS" WITHOUT WARRANTY OF ANY KIND. WE MAKE NO WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE ACCURACY OR COMPLETENESS OF INFORMATION ON THIS WEBSITE.
To the maximum extent permitted by applicable law, La Habra Sunrooms and Patios shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising out of or related to our services or this website, including but not limited to loss of use, loss of revenue, or loss of data, even if we have been advised of the possibility of such damages.
Our total liability to you for any claim arising out of or related to our services shall not exceed the total amount paid by you to us for the specific project giving rise to the claim. This limitation does not apply to claims arising from our gross negligence, willful misconduct, or fraud.
All content on this website, including text, images, graphics, and logos, is the property of La Habra Sunrooms and Patios or its content suppliers and is protected by applicable intellectual property laws. You may not reproduce, distribute, or create derivative works from any content on this website without our prior written permission.
If a dispute arises out of or relates to these Terms or our services, the parties agree to first attempt to resolve it through good-faith negotiation. If negotiation is unsuccessful within 30 days of written notice of the dispute, the parties agree to attempt mediation before pursuing any other legal remedy.
Nothing in this section limits either party from seeking emergency injunctive or other equitable relief in a court of competent jurisdiction where necessary to protect property or prevent irreparable harm.
These Terms and Conditions, and any dispute arising out of or related to them or our services, shall be governed by and construed in accordance with the laws of the State of California, without regard to its conflict of law principles. Any legal proceedings shall be brought in the courts of Orange County, California.
We reserve the right to update or modify these Terms and Conditions at any time. Changes will be posted to this page with an updated effective date. Your continued use of our website or services after any change constitutes your acceptance of the revised terms. We encourage you to review this page periodically.
Questions about these Terms and Conditions may be directed to:
La Habra Sunrooms and Patios
321 N Hazel St
La Habra, CA 90631